2020-02-16
Blogs

Applying for an extension of time

Home / Knowledge base / Applying for an extension of time

Posted by Philip Harris on 28 September 2012

Philip Harris - Construction Solicitor
Philip Harris Partner & Solicitor-Advocate

Applications for an extension of time should be made as soon as practicable, setting out the relevant event and explaining the grounds and period of extension required. Generally, under the main JCT contracts, an application is not a pre-requisite to getting an extension.

The architect or employer’s agent has review periods for considering extension applications.

Although, unquestionably, applications for an extension of time should be made as soon as practicable, setting out the relevant event and explaining the grounds and period of extension required, generally under the main JCT contracts an application is not a pre-requisite to getting an extension.  The architect or employer’s agent has review periods for considering extension applications.  The first review period is normally 12 weeks or up to practical completion (if sooner) and this applies to a request for an extension during the course of the works.  

At practical completion there is a further review period, again normally 12 weeks, during which the architect or employer’s agent must consider whether an extension is due to the contractor whether or not an extension has been applied for.  It is this second review period which saves the contractor who has failed to apply for an extension of time because the architect must consider whether an extension is properly due whether or not an application has been made.  Of course it may be open to the architect to say that without an application for extension of time, he had no reasonable grounds for believing that an extension of time was due.                    

Note, that after each extension granted, the architect must put in place a new non-completion certificate to replace the old one, otherwise the earlier non-completion certificate is invalidated by the new extension and liquidated damages cannot be taken.

About the author

Philip Harris

Partner & Solicitor-Advocate

Philip has 30 years’ experience as a construction solicitor and advises on all aspects of construction law.

Philip Harris

Philip has 30 years’ experience as a construction solicitor and advises on all aspects of construction law.

Recent articles

30 July 2020 Rethinking the landlord / tenant relationship

We have been following the travails of the high street for over 12 months where changing shopping habits, business rates and rent increases have been contributing to a growing strain on many landlord / tenant relationships. The Covid-19 pandemic has not only turned a bad situation critical for many retailers and hospitality venues but has also turned the spotlight on the wider commercial sector too. Almost all businesses operating across the country have suffered financially to a greater or lesser extent as result of the economic downturn precipitated by the imposition of lockdown in March.

Read article
30 July 2020 Bankrupts fail in claim to have interests in land revested in them

The claim by Mr and Mrs Brake (Brake v Swift), heard in the High Court in May, to have a cottage and adjacent land revested in them under Section 283A of the Insolvency Act 1986, was set against a background of convoluted litigation extending over a number of years, described by Matthews HHJ as ‘complex’. The claimants had been made bankrupt in 2015 and the matter before the Court concentrated on whether or not the property concerned was, indeed, the claimants’ principal residence at the time of the bankruptcy.

Read article
29 July 2020 Remote witnessing of wills – a sign of the times

The law governing how a will is witnessed dates back to 1837 and for good reason. The requirement for two people (neither of whom can inherit from the will they are witnessing) to be physically present at the signing of a will is designed to, among other things, prevent fraud and the exercise of undue influence. That is, until the Covid-19 pandemic struck.

Read article
Contact
How can we help?
01926 732512
CALL BACK